BID BOND:
Bid security equal to five percent (5%) of the total bid must accompany each Bid.
Acceptable formats: AIA document A310, EJCDC form, or format acceptable to the surety. Bid Bond form also available on City of Ocala website using this link: Bid Bond Form
|
UPLOAD EXECUTED BID BOND HERE
Max. File Size you can upload is: 50MB. *.exe files will not be accepted
|
CARE OF WORK:
The Contractor shall be responsible for all damages to persons or property that occur as a result of his fault or negligence in connection with the prosecution of the work and shall be responsible for the proper care and protection of all work performed until completion and final acceptance, whether or not the same has been covered in whole or in part by payments made by the City of Ocala.
The Contractor shall avoid damaging sidewalks, streets, curbs, pavements, utilities, structures or any other property (except that which is to be replaced or removed) either on or adjacent to the site. He shall repair, at his own expense and in manner satisfactory to the City of Ocala, any damage thereto caused by his operations.
All water and gas mains, all sewer and other pipes, and all conduits and other underground work of any nature, crossing or projecting into any trench or excavation and all appurtenances thereto, such as Cast Iron Valve Boxes, curb boxes, manhole casting, etc., shall be sufficiently and adequately shored and supported by timber and planking and protected by the Contractor from injury, and any damage or injury thereto shall be repaired by the Contractor at his own expense to the satisfaction of the Engineer.
|
OFFER AND ACCEPTANCE:
Any submitted bid or proposal is your contractual, legally bound obligation in the absence of a written contract when said offer is accepted by the City. The City reserves the right to request modification of the Bidder's offer to more fully meet the needs of the City, and any further offer is binding upon the Bidder.
In case of default by the Bidder after acceptance by the City, the City may take action as it deems appropriate including legal action for damages or specific performance.
Owner/Authorized Company Representative Initials:
|
ACCESS TO RECORDS AND REPORTS:
49 U.S.C. § 5325(g), 2 C.F.R. § 200.333, 49 C.F.R. part 633
The record keeping and access requirements apply to all contracts funded in whole or in part with FTA funds. Under 49 U.S.C. § 5325(g), FTA has the right to examine and inspect all records, documents, and papers, including contracts, related to any FTA project financed with Federal assistance authorized by 49 U.S.C. Chapter 53.
The record keeping and access requirements extend to all third party contractors and their contracts at every tier and sub-recipients and their subcontracts at every tier.
Record Retention. The Contractor will retain, and will require its subcontractors of all tiers to retain, complete and readily accessible records related in whole or in part to the contract, including, but not limited to, data, documents, reports, statistics, sub-agreements, leases, subcontracts, arrangements, other third party agreements of any type, and supporting materials related to those records.
Retention Period. The Contractor agrees to comply with the record retention requirements in accordance with 2 C.F.R. § 200.333. The Contractor shall maintain all books, records, accounts and reports required under this Contract for a period of at not less than three (3) years after the date of termination or expiration of this Contract, except in the event of litigation or settlement of claims arising from the performance of this Contract, in which case records shall be maintained until the disposition of all such litigation, appeals, claims or exceptions related thereto.
Access to Records. The Contractor agrees to provide sufficient access to FTA and its contractors to inspect and audit records and information related to performance of this contract as reasonably may be required.
Access to the Sites of Performance. The Contractor agrees to permit FTA and its contractors access to the sites of performance under this contract as reasonably may be required.
|
ADA NEEDS:
Please call the procurement professional shown on this listing forty-eight (48) hours in advance so arrangements can be made if reasonable accommodations are needed for you to participate in any meeting.
|
AUDIT AND INSPECTION OF RECORDS:
The contractor shall permit the authorized representatives of the U.S. Department of Transportation and of the Comptroller General of the United States to inspect and audit all data and records of the contractor relating to its performance and its subcontracts under this contract with which federal funds are used from the date of the contract through and until the expiration of three years after completion of the contract. This section excludes the inspection data and records required in Part III: Qualify Assurance Provisions. The inspection and audit provided in this section does not include an audit of the manufacturer's cost and/or profit, with the execution of single bid or sole source situations.
|
MAINTENANCE AND GUARANTEE BOND:
The successful Bidder is required to furnish a Maintenance and Guarantee Bond for a period of 3 year(s) for labor and 3 year(s) for materials from the date the project is completed.
|
AWARDED CONTRACT FAILURE - BIDDING SUSPENSION
I understand and agree to the following:
Bidders who submit a bid to the City of Ocala and fail to fulfill the contract term, for any reason, will be subject to future bidding suspension for year (1), and up to a possible three (3) year bid debarment for serious contractual failures.
Owner/Authorized Company Representative initials:
|
|
The City reserves the right to re-open bidding for a Best-and-Final offer.
|
PUBLIC CONSTRUCTION BOND:
The successful Bidder shall furnish to the City, as Owner, a certified, and recorded Public Construction Bond, drafted per Florida Statute 255.05, in an amount not less than: $ TOTAL CONTRACT AMOUNT
This Public Construction Bond is required to guarantee the bidder will deliver a completed project, and will pay all persons supplying them with labor and/or material for the project.
|
BIDDER CONTRACTS:
Bidder contracts/agreements will not be accepted in most cases. If a contract is required, only City of Ocala contracts will be used for all goods and services. The requirement of bidder contracts and/or bidder written terms and conditions may result in bid rejection. The City will consider adding appropriate bidder clauses into our contract; please upload any desired clauses with your solicitation response.
|
BUY AMERICA REQUIREMENTS:
49 U.S.C. 5323(j), 49 C.F.R. part 661
The Buy America requirements apply to the following types of contracts: Construction Contracts and Acquisition of Goods or Rolling Stock (valued at more than $150,000). The Buy America requirements flow down from FTA recipients and sub-recipients to first tier contractors, who are responsible for ensuring that lower tier contractors and subcontractors are in compliance.
The contractor agrees to comply with 49 U.S.C. 5323(j) and 49 C.F.R. part 661, which provide that Federal funds may not be obligated unless all steel, iron, and manufactured products used in FTA funded projects are produced in the United States, unless a waiver has been granted by FTA or the product is subject to a general waiver. General waivers are listed in 49 C.F.R. § 661.7. Separate requirements for rolling stock are set out at 49 U.S.C. 5323(j)(2)(C) and 49 C.F.R. § 661.11.
A bidder or offeror must submit to the FTA recipient (City of Ocala) the appropriate Buy America certification below with its bid. Bids or offers that are not accompanied by a completed Buy America certification will be rejected as non-responsive.
---------COMPLETE ONE OF THE BELOW CERTIFICATIONS----------
Certificate of Compliance with Buy America Requirements:
The bidder or offeror hereby certifies that it will comply with the requirements of 49 U.S.C. 5323(j)(1), and the applicable regulations in 49 C.F.R. part 661.
Date:
Typed signature:
Company:
Name:
Title:
-------------------------------------------------------------------------------------------------
Certificate of Non-Compliance with Buy America Requirements:
The bidder or offeror hereby certifies that it cannot comply with the requirements of 49 U.S.C. 5323(j), but it may qualify for an exception to the requirement pursuant to 49 U.S.C. 5323(j)(2), as amended, and the applicable regulations in 49 C.F.R. § 661.7.
Date:
Typed Signature:
Company:
Name:
Title:
|
CLARIFICATIONS AND CORRECTIONS:
The City of Ocala reserves the right, where it may serve the City’s best interest, to request additional information or clarifications from bidders/proposers, or to allow corrections of errors or omissions.
|
CITY OF OCALA STANDARD SPECIFICATIONS FOR CONSTRUCTION (EFFECTIVE FEBRUARY 16, 2023):
For this project, the Contractor will be bound by these specifications and conditions:
STANDARD SPECIFICATIONS FOR CONSTRUCTION OF STREETS, STORMWATER, TRAFFIC, WATER AND SEWER INFRASTRUCTURE: Standard Specifications for Construction (Effective: 02/16/2023)
|
CONFIDENTIAL, PROPRIETARY, OR TRADE SECRET MATERIAL:
Bids or quotes received by the City pursuant to its solicitations are exempt from public disclosure until such time that the City provides notice of an intended decision or until thirty (30) days after opening the bids or quotes, whichever is earlier. If the City rejects all bids or quotes pursuant to this solicitation and provides notice of its intent to reissue the solicitation, then the rejected bids or quotes remain exempt from public disclosure until such time that the City provides notice of an intended decision concerning the reissued solicitation or until the City withdraws the reissued solicitation. A bid, quote, or reply shall not be exempt from public disclosure longer than twelve (12) months after the City's initial notice rejecting all bids, quotes, or replies.
ANY MATERIAL SUBMITTED IN RESPONSE TO THIS SOLICITATION WILL BECOME A PUBLIC RECORD PURSUANT TO CHAPTER 119, FLORIDA STATUTES. THIS INCLUDES MATERIAL WHICH THE RESPONDING BIDDER MAY CONSIDER TO BE CONFIDENTIAL, PROPRIETARY, OR A TRADE SECRET. ANY CLAIM OF CONFIDENTIALITY SHALL BE WAIVED UPON SUBMISSION, EFFECTIVE AFTER OPENING PURSUANT TO CHAPTER 119, FLORIDA STATUTES.
Owner/Authorized Company Representative initials:
|
CONSTRUCTION SURVEY LAYOUT:
The work to be performed shall be for the survey work necessary to establish proper alignments, right of way, easements, bench marks, elevations and grade stakes to complete all phases of this contract.
|
CONFLICT OF INTEREST:
Disclose the name(s) of any employee, officer, director, shareholder, or agent of your firm that is also a City of Ocala employee or public official:
Disclose the name(s) of any City of Ocala employee or public official that is a known relative of an employee, officer, director, shareholder, or agent of your firm:
Failure to disclose known conflicts of interest may result in bid rejection and/or contract termination, if awarded.
City of Ocala employees who have a 5% or more interest in a bidder's firm must also complete an "Officer and Employee Disclosure Statement" which can be obtained at www.bidocala.com under Vendor Resources. This form includes instructions and relative Florida statutes. Failure to complete this form, if applicable, may result in bid rejection.
|
CIVIL RIGHTS LAWS AND REGULATIONS AND REQUIREMENTS:
The following Federal Civil Rights laws and regulations apply to all contracts. The Civil Rights requirements flow down to all third party contractors and their contracts at every tier.
Civil Rights and Equal Opportunity: The City of Ocala is an Equal Opportunity Employer. As such, the City of Ocala agrees to comply with all applicable Federal civil rights laws and implementing regulations. Apart from inconsistent requirements imposed by Federal laws or regulations, the City of Ocala agrees to comply with the requirements of 49 U.S.C. § 5323(h) (3) by not using any Federal assistance awarded by FTA to support procurements using exclusionary or discriminatory specifications.
Under this Agreement, the Contractor shall at all times comply with the following requirements and shall include these requirements in each subcontract entered into as part thereof.
1. Nondiscrimination. In accordance with Federal transit law at 49 U.S.C. § 5332, the Contractor agrees that it will not discriminate against any employee or applicant for employment because of race, color, religion, national origin, sex, disability, or age. In addition, the Contractor agrees to comply with applicable Federal implementing regulations and other implementing requirements FTA may issue.
2. Race, Color, Religion, National Origin, Sex. In accordance with Title VII of the Civil Rights Act, as amended, 42 U.S.C. § 2000e et seq., and Federal transit laws at 49 U.S.C. § 5332, the Contractor agrees to comply with all applicable equal employment opportunity requirements of U.S. Department of Labor (U.S. DOL) regulations, "Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor," 41 C.F.R. chapter 60, and Executive Order No. 11246, "Equal Employment Opportunity in Federal Employment," September 24, 1965, 42 U.S.C. § 2000e note, as amended by any later Executive Order that amends or supersedes it, referenced in 42 U.S.C. § 2000e note. The Contractor agrees to take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, national origin, or sex (including sexual orientation and gender identity). Such action shall include, but not be limited to, the following: employment, promotion, demotion or transfer, recruitment or recruitment advertising, layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue.
3. Age. In accordance with the Age Discrimination in Employment Act, 29 U.S.C. §§ 621-634, U.S. Equal Employment Opportunity Commission (U.S. EEOC) regulations, “Age Discrimination in Employment Act,” 29 C.F.R. part 1625, the Age Discrimination Act of 1975, as amended, 42 U.S.C. § 6101 et seq., U.S. Health and Human Services regulations, “Nondiscrimination on the Basis of Age in Programs or Activities Receiving Federal Financial Assistance,” 45 C.F.R. part 90, and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees to refrain from discrimination against present and prospective employees for reason of age. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue.
4. Disabilities. In accordance with section 504 of the Rehabilitation Act of 1973, as amended, 29 U.S.C. § 794, the Americans with Disabilities Act of 1990, as amended, 42 U.S.C. § 12101 et seq., the Architectural Barriers Act of 1968, as amended, 42 U.S.C. § 4151 et seq., and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees that it will not discriminate against individuals on the basis of disability. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue.
|
CONTRACT TIME:
Contractor agrees, as a condition for submitting a bid, that the Work will be substantially completed within 75 day(s), and completed and ready for final payment in accordance with the Agreement within 10 day(s) after substantial completion.
The Contractor agrees to commence work on the date specified in a written “Notice to Proceed” by the City for each project assigned. Such “Notice to Proceed” will be issued at the pre-construction conference, not to exceed 10 days from the preconstruction date.
The Contractor must be able to mobilize and begin construction no later than 10 working days after notification, and complete the project by the time limit specified in the “Notice to Proceed.” At no time will the Contractor be allowed to lag behind.
|
CLEAN AIR ACT AND FEDERAL WATER POLLUTION CONTROL ACT:
42 U.S.C. §§ 7401 – 7671q; 33 U.S.C. §§ 1251-1387, 2 C.F.R. part 200, Appendix II (G)
The Clean Air and Clean Water Act requirements apply to each contract and subcontract exceeding $150,000.
The Clean Air Act and Federal Water Pollution Control Act requirements extend to all third party contractors and their contracts at every tier and sub-recipients and their subcontracts at every tier.
The Contractor agrees:
1) It will not use any violating facilities;
2) It will report the use of facilities placed on or likely to be placed on the U.S. EPA “List of Violating Facilities;”
3) It will report violations of use of prohibited facilities to FTA; and
4) It will comply with the inspection and other requirements of the Clean Air Act, as amended, (42 U.S.C. §§ 7401 – 7671q); and the Federal Water Pollution Control Act as amended, (33 U.S.C. §§ 1251-1387).
|
CONTRACTOR’S EMPLOYEES:
The foreman, employees, mechanics and other employed by the Contractor shall be skilled in the work given to them to do. Any employee of the Contractor who may use profane or abusive language to the Engineer or any Inspector, or otherwise impede or embarrass him in the performance of his duties, or who obstructs the progress of the work, shall upon the request of the Engineer, be immediately discharged and not again employed without consent of the Engineer.
In doing any work contemplated by this contract, eight (8) hours shall constitute a legal day’s work by any laborer or workman employed by said Contractor hereon.
|
CONTRACT WORK HOURS AND SAFETY STANDARDS:
40 U.S.C. §§ 3701-3708, 29 C.F.R. part 5
The Contract Work Hours and Safety Standards Act apply to all FTA funded contracts in excess of $100,000 that involve the employment of mechanics or laborers. These requirements extend to all third party contractors and their contracts at every tier and sub-recipients and their subcontracts at every tier.
Contract Work Hours and Safety Standards:
For all contracts in excess of $100,000 that involve the employment of mechanics or laborers, the Contractor shall comply with the Contract Work Hours and Safety Standards Act (40 U.S.C. §§ 3701-3708), as supplemented by the DOL regulations at 29 C.F.R. part 5. Under 40 U.S.C. § 3702 of the Act, the Contractor shall compute the wages of every mechanic and laborer, including watchmen and guards, on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. § 3704 are applicable to construction work and provide that no laborer or mechanic be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchase of supplies or materials or articles ordinarily available on the open market, or to contracts for transportation or transmission of intelligence.
In the event of any violation of the clause set forth herein, the Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, the Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of this clause in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by this clause.
The FTA shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the Contractor or subcontractor under any such contract or any other Federal contract with the same prime Contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime Contractor, such sums as may be determined to be necessary to satisfy any liabilities of such Contractor or subcontractor for unpaid wages and liquidated damages as provided in this section.
The Contractor or subcontractor shall insert in any subcontracts the clauses set forth in this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime Contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in this agreement.
Contract Work Hours and Safety Standards for Awards Not Involving Construction:
The Contractor shall comply with all federal laws, regulations, and requirements providing wage and hour protections for non-construction employees, in accordance with 40 U.S.C. § 3702, Contract Work Hours and Safety Standards Act, and other relevant parts of that Act, 40 U.S.C. § 3701 et seq., and U.S. DOL regulations, “Labor Standards Provisions Applicable to Contracts Covering Federally Financed and Assisted Construction (also Labor Standards Provisions Applicable to Non-construction Contracts Subject to the Contract Work Hours and Safety Standards Act),” 29 C.F.R. part 5.
The Contractor shall maintain payrolls and basic payroll records during the course of the work and shall preserve them for a period of three (3) years from the completion of the contract for all laborers and mechanics, including guards and watchmen, working on the contract. Such records shall contain the name and address of each such employee, social security number, correct classifications, hourly rates of wages paid, daily and weekly number of hours worked, deductions made, and actual wages paid.
Such records maintained under this paragraph shall be made available by the Contractor for inspection, copying, or transcription by authorized representatives of the FTA and the Department of Labor, and the Contractor will permit such representatives to interview employees during working hours on the job.
The contractor shall require the inclusion of the language of this clause within subcontracts of all tiers.
|
FINAL ESTIMATE FOR PAYMENT:
After the Contractor has approved, or approved under protest, the Engineer’s final estimate, final payment will be processed based on the entire sum, or the undisputed sum in case of approval under protest, determined to be due the Contractor less all previous payments and all other amounts to be deducted under the provisions of the contact.
|
FLORIDA TRENCH SAFETY ACT CERTIFICATE OF COMPLIANCE:
CERTIFICATION
I understand that Chapter 90.96 of the Laws of Florida (The Trench Safety Act) requires me to comply with OSHA Standard 29 C.F.R.s. 1926.650 Subpart P. I will comply with The Trench Safety Act, and I will design and provide trench safety systems at all trench excavations in excess of five feet in depth for this project.
SUMMARY
1. For all excavations that exceed five feet in depth from the existing surface elevation, the Bidder
must assure that all provisions of the Florida State Bill CS/SB 2626, the 1 990 ''Trench Safety
Act'' shall be met.
2. No separate payment will be made for these items, but they must be identified in this Bid or Certificate of Compliance.
COST
The estimated cost imposed by compliance with The Trench Safety Act, which is included as part of the lump sum amount or unit prices, is as follows: $
BIDDER'S STATEMENT
The current trench safety standards in effect are Occupational Safety and Health Administration (OSHA)
Excavating Safety Standard 29 C. F. R. Part 1 926.650 Subpart P.
Check box(es) below to comply with the 1990 "Trench Safety Act":
Shoring Sloping Trench Box Other
Owner/Authorized Company Representative initials:
|
DELAYS AND DAMAGES:
The Bidder agrees to make no claim for extra or additional costs attributable to any delays or inefficiencies in the performance of this contract occasioned by any act by the City except as provided in the agreement. The Bidder also agrees that any such delay or inefficiency shall be compensated for solely by an extension of time to complete the performance of the work in accordance with the provision in the standard specification.
|
DISADVANTAGED BUSINESS ENTERPRISE (DBE) REQUIREMENTS:
49 CFR Part 26
The Disadvantaged Business Enterprise (DBE) program applies to all prime contracts (excluding transit vehicle purchases).
The DBE contracting requirements flow down to all third party contractors and their contracts at every tier.
Contractor agrees to ensure that disadvantaged business enterprises as defined in 49 CFR Part 26 have the maximum opportunity to participate in the performance of contracts and subcontracts under this solicitation. In this regard, contractors shall take all necessary and reasonable steps in accordance with 49 CFR Part 26 to ensure that disadvantaged business enterprises have the maximum opportunity to compete for contracts, when applicable.
Contractor shall not discriminate on the basis of race, creed color, national origin, age, or sex in the award and performance of contracts.
|
LIQUIDATED DAMAGES:
The Contractor shall pay the City $ 1,699 for each calendar day that expires after the time specified for Substantial Completion, until the Work is substantially completed. After Substantial Completion, if the Contractor shall neglect, refuse, or fail to complete the remaining Work within the Contract Times or any proper extension thereof granted by the City, the Contractor shall pay an additional $ 200 per day for each calendar day that expires after the time specified until Final Completion and acceptance of the project by the City.
The liquidated damages set forth herein shall not be accumulative. If Substantial Completion of the Work is not met within the time specified for final completion of all Work, the liquidated damages shall continue to be at the rate or rates specified for default on Substantial Completion until Substantial Completion is attained. If the Work is not then finally completed, the rate or rates specified for default on final completion shall apply until final completion is attained.
The City shall have the right to deduct the liquidated damages from any money in its hands, otherwise due, or to become due, to the Contractor, or to initiate applicable dispute resolution procedures and to recover liquidated damages for non-performance of this Contract within the time stipulated.
Nothing in this section is intended to limit the right to obtain injunctive relief or any and all relief as may be appropriate. Permission allowing the Contractor to continue and finish any part of the work after the time fixed for its completion or after the date to which the time for completion may have been extended shall in no way operate as a waiver on the part of the City of any of its rights under this Agreement.
|
INSPECTION AND ACCEPTANCE:
All goods and/or services provided under the resulting agreement are subject to inspection and acceptance by an authorized representative of City. Payment shall not be authorized until the goods and/or services have been received, accepted, and properly invoiced. City reserves the right to have rejected goods replaced by Vendor at the purchase price stipulated in this Agreement; or to return the rejected goods for full credit at the price charged. Transportation costs and any additional costs will be borne by Vendor in each instance. City’s rights with respect to rejection of material are not waived by failure to notify Vendor immediately upon receipt of delivery.
|
MANUFACTURER SERVICES:
The Contractor shall furnish manufacturer’s representative as required to resolve assembly or installation problems with their products and systems. The Contractor shall conduct, with the assistance of the manufacturer/supplier’s representative, start-up and operational tests on the equipment and system.
|
OWNER:
The Project has been designed for the City of Ocala ("Owner"), who may also be referred to in the Bid Documents as Project Manager, or the Engineer.
All work and material furnished under this contract shall be furnished under the direction of, and to the satisfaction and approval of the Owner. Should any dispute arise as to the quality or fitness of the materials or workmanship, the decision shall rest strictly with the Owner, and shall be based upon the stated requirements in the Bid and Contractor’s Bid response. This power and authority shall not extend to the actual execution of the work which shall be under the control of the Contractor, and for which the Contractor alone is responsible.
The Contractor warrants all materials, equipment, or supplies furnished and all work performed under this contract will be new, of specified quality, free from faults and defects, free from faulty design, and of sufficient size and capacity and of proper materials to meet in all respects the requirements of the contract. The Contractor shall obtain for the benefit of the Owner all standard warranties of subcontractors, suppliers, and manufactures of all material, equipment or supplies manufactured, furnished or installed.
|
PROGRESS PAYMENTS AND RETAINAGE:
Progress payments will be made at least once each month as work is completed. Retainage under the Contract Documents will be held as collateral security to secure completion of the Work. Payment will be made each month in the amount of ninety-five percent (95%) of the estimated value of the services provided at the job site during the previous calendar month, provided the work is reasonably complete. The Owner will withhold five percent (5%) of the amount of each progress payment. The last payment due along with the release of retainage for this contract will be paid by the Owner to the Contractor only after the Contractor has furnished the Owner the Consent of Surety of the recorded bond for final payment.
|
PERFORMANCE EVALUATION:
At the end of the service period, the City may evaluate vendor performance. This evaluation will become public record.
|
GOVERNMENT-WIDE DEBARMENT AND SUSPENSION:
2 C.F.R. part 180, 2 C.F.R part 1200, 2 C.F.R. § 200.213, 2 C.F.R. part 200 Appendix II (I), Executive Order 12549, Executive Order 12689
A contract award (of any tier) in an amount expected to equal or exceed $25,000 or a contract award at any tier for a federally required audit (irrespective of the contract amount) must not be made to parties listed on the government-wide exclusions in the System for Award Management (SAM), in Accordance with the OMB guidelines at 2 C.F.R. part 180.
These requirements extend to all third party contractors and their contracts at every tier and sub-recipients and their subcontracts at every tier.
Debarment, Suspension, Ineligibility and Voluntary Exclusion:
The Contractor shall comply and facilitate compliance with U.S. DOT regulations, “Nonprocurement Suspension and Debarment,” 2 C.F.R. part 1200, which adopts and supplements the U.S. Office of Management and Budget (U.S. OMB) “Guidelines to Agencies on Governmentwide Debarment and Suspension (Nonprocurement),” 2 C.F.R. part 180. These provisions apply to each contract at any tier of $25,000 or more, and to each contract at any tier for a federally required audit (irrespective of the contract amount), and to each contract at any tier that must be approved by an FTA official irrespective of the contract amount. As such, the Contractor shall verify that its principals, affiliates, and subcontractors are eligible to participate in this federally funded contract and are not presently declared by any Federal department or agency to be:
a) Debarred from participation in any federally assisted Award;
b) Suspended from participation in any federally assisted Award;
c) Proposed for debarment from participation in any federally assisted Award;
d) Declared ineligible to participate in any federally assisted Award;
e) Voluntarily excluded from participation in any federally assisted Award; or
f) Disqualified from participation in ay federally assisted Award.
By signing and submitting its bid or proposal, the bidder or proposer certifies as follows:
The certification in this clause is a material representation of fact relied upon by the City of Ocala. If it is later determined by the City of Ocala that the bidder or proposer knowingly rendered an erroneous certification, in addition to remedies available to the City of Ocala, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. The bidder or proposer agrees to comply with the requirements of 2 C.F.R. part 180, subpart C, as supplemented by 2 C.F.R. part 1200, while this offer is valid and throughout the period of any contract that may arise from this offer. The bidder or proposer further agrees to include a provision requiring such compliance in its lower tier covered transactions.
|
PROGRESS REPORTS/UPDATED SCHEDULES:
A progress report and updated project schedule must be submitted with each monthly pay request indicating the Percent of Services Completed to Date. This report will serve as support for payment to Contractor and the basis for payment in the event project is suspended or abandoned.
|
FLORIDA STATUTE 287.133: Public Entity Crime; denial or revocation of the right to transact business with public entities.
Vendor on its behalf and its affiliates agrees and affirms that it has not been placed on the convicted vendor list following a conviction of a public entity crime as provided for in Section 287.133(2)(a), Florida Statutes, which states:
a person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases or real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO, for a period of 36 months from the date of being placed on the convicted vendor list.
Owner/Authorized Company Representative initials:
|
LOBBYING RESTRICTIONS:
31 U.S.C. § 1352, 2 C.F.R. § 200.450, 2 C.F.R. part 200 appendix II (J), 49 C.F.R. part 20
The lobbying requirements apply to all contracts and subcontracts of $100,000 or more at any tier under a Federal grant.
The undersigned certifies, to the best of his or her knowledge and belief, that:
1. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of an agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.
2. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, “Disclosure Form to Report Lobbying,” in accordance with its instructions.
3. The undersigned shall require that the language of this certification be included in the award documents for all sub-awards at all tiers (including subcontracts, sub-grants, and contracts under grants, loans, and cooperative agreements) and that all sub-recipients shall certify and disclose accordingly.
This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by section 1352, title 31, U.S. Code. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.
Typed Signature of Contractor's Authorized Official:
Name and Title of Contractor's Authorized Official:
Date:
|
FDOT STANDARD SPECIFICATIONS FOR ROAD AND BRIDGE CONSTRUCTION (LATEST EDITION):
This project will require the Contractor to follow these specifications:
Florida Department of Transportation Standard Specifications for Road and Bridge Construction (latest edition):
http://www.fdot.gov/programmanagement/Implemented/SpecBooks/
|
REFERENCES:
References within the previous three years are preferred.
REFERENCE #1
Company Name:
Contact Person:
Phone Number:
Email Address:
Date of Service:
 | Loading… |
|
| 18 | 28 | 29 | 30 | 1 | 2 | 3 | 4 |
| 19 | 5 | 6 | 7 | 8 | 9 | 10 | 11 |
| 20 | 12 | 13 | 14 | 15 | 16 | 17 | 18 |
| 21 | 19 | 20 | 21 | 22 | 23 | 24 | 25 |
| 22 | 26 | 27 | 28 | 29 | 30 | 31 | 1 |
| 23 | 2 | 3 | 4 | 5 | 6 | 7 | 8 |
|
|
| Jan | Feb | Mar | Apr |
| May | Jun | Jul | Aug |
| Sep | Oct | Nov | Dec |
to
| Loading… |
|
| 18 | 28 | 29 | 30 | 1 | 2 | 3 | 4 |
| 19 | 5 | 6 | 7 | 8 | 9 | 10 | 11 |
| 20 | 12 | 13 | 14 | 15 | 16 | 17 | 18 |
| 21 | 19 | 20 | 21 | 22 | 23 | 24 | 25 |
| 22 | 26 | 27 | 28 | 29 | 30 | 31 | 1 |
| 23 | 2 | 3 | 4 | 5 | 6 | 7 | 8 |
|
|
| Jan | Feb | Mar | Apr |
| May | Jun | Jul | Aug |
| Sep | Oct | Nov | Dec |
Contract Value:
Contract Details and/or Description:
|
REFERENCE #2
Company Name:
Contact Person:
Phone Number:
Email Address:
Date of Service:
| Loading… |
|
| 18 | 28 | 29 | 30 | 1 | 2 | 3 | 4 |
| 19 | 5 | 6 | 7 | 8 | 9 | 10 | 11 |
| 20 | 12 | 13 | 14 | 15 | 16 | 17 | 18 |
| 21 | 19 | 20 | 21 | 22 | 23 | 24 | 25 |
| 22 | 26 | 27 | 28 | 29 | 30 | 31 | 1 |
| 23 | 2 | 3 | 4 | 5 | 6 | 7 | 8 |
|
|
| Jan | Feb | Mar | Apr |
| May | Jun | Jul | Aug |
| Sep | Oct | Nov | Dec |
to
| Loading… |
|
| 18 | 28 | 29 | 30 | 1 | 2 | 3 | 4 |
| 19 | 5 | 6 | 7 | 8 | 9 | 10 | 11 |
| 20 | 12 | 13 | 14 | 15 | 16 | 17 | 18 |
| 21 | 19 | 20 | 21 | 22 | 23 | 24 | 25 |
| 22 | 26 | 27 | 28 | 29 | 30 | 31 | 1 |
| 23 | 2 | 3 | 4 | 5 | 6 | 7 | 8 |
|
|
| Jan | Feb | Mar | Apr |
| May | Jun | Jul | Aug |
| Sep | Oct | Nov | Dec |
Contract Value:
Contract Details and/or Description:
|
NO GOVERNMENT OBLIGATION TO THIRD PARTIES:
The No Obligation clause applies to all third party contracts that are federally funded. The No Obligation clause extends to all third party contractors and their contracts at every tier and sub-recipients and their subcontracts at every tier.
The Recipient and Contractor acknowledge and agree that, notwithstanding any concurrence by the Federal Government in or approval of the solicitation or award of the underlying Contract, absent the express written consent by the Federal Government, the Federal Government is not a party to this Contract and shall not be subject to any obligations or liabilities to the Recipient, Contractor or any other party (whether or not a party to that contract) pertaining to any matter resulting from the underlying Contract. The Contractor agrees to include the above clause in each subcontract financed in whole or in part with Federal assistance provided by the FTA. It is further agreed that the clause shall not be modified, except to identify the subcontractor who will be subject to its provisions.
|
REQUESTED AND ADDITIONAL DOCUMENTS
Upload any requested and additional documents here:
Max. File Size you can upload is: 50MB. *.exe files will not be accepted
|
PROGRAM FRAUD AND FALSE OR FRAUDULENT STATEMENTS AND RELATED ACTS:
49 U.S.C. § 5323(l) (1), 31 U.S.C. §§ 3801-3812, 18 U.S.C. § 1001, 49 C.F.R. part 31
The Program Fraud clause applies to all third party contracts that are federally funded. The Program Fraud clause extends to all third party contractors and their contracts at every tier and subrecipients and their subcontracts at every tier. These requirements flow down to contractors and subcontractors who make, present, or submit covered claims and statements.
The Contractor acknowledges that the provisions of the Program Fraud Civil Remedies Act of 1986, as amended, 31 U.S.C. § 3801 et seq. and U.S. DOT regulations, "Program Fraud Civil Remedies," 49 C.F.R. part 31, apply to its actions pertaining to this Project. Upon execution of the underlying contract, the Contractor certifies or affirms the truthfulness and accuracy of any statement it has made, it makes, it may make, or causes to be made, pertaining to the underlying contract or the FTA assisted project for which this contract work is being performed. In addition to other penalties that may be applicable, the Contractor further acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification, the Federal Government reserves the right to impose the penalties of the Program Fraud Civil Remedies Act of 1986 on the Contractor to the extent the Federal Government deems appropriate.
The Contractor also acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification to the Federal Government under a contract connected with a project that is financed in whole or in part with Federal assistance originally awarded by FTA under the authority of 49 U.S.C. chapter 53, the Government reserves the right to impose the penalties of 18 U.S.C. § 1001 and 49 U.S.C. § 5323(l) on the Contractor, to the extent the Federal Government deems appropriate.
The Contractor agrees to include the above two clauses in each subcontract financed in whole or in part with Federal assistance provided by FTA. It is further agreed that the clauses shall not be modified, except to identify the subcontractor who will be subject to the provisions.
|
TRAFFIC CONTROL AND BARRICADES:
The Contractor shall mitigate impact on local traffic conditions to all extents possible. The Contractor is responsible for establishing and maintaining appropriate traffic control and barricades. The Contractor shall provide sufficient signing, flagging and barricading to ensure the safety of Vehicular and Pedestrian traffic at all locations where work is being done for this project.
In addition to the requirements set forth in the bid, the Contractor shall maintain at all times a good and sufficient fence, railing or barrier around all exposed portions of said work in such a manner as to warn vehicular and pedestrian traffic of hazardous conditions.
Should the Contractor fail to properly barricade his work or stored material sites in the manner outlined above, the City may have the necessary barricading done, and all cost incurred for said barricading shall be charged to the Contractor.
|
REQUIRED LICENSES AND CERTIFICATIONS:
My firm and/or sub-contractors can comply with the license and certification requirements in the scope and/or this listing.
Vendor shall upload all licenses and/or certifications with their response and must submit required licenses and certifications immediately upon request from the City.
Owner/Authorized Company Representative initials:
|
TIMELY PAYMENT FOR PURCHASES OF CONSTRUCTION SERVICES:
Payments shall be made no later than the time periods established by Section 218.735, Florida Statutes.
Prime contractors shall pay subcontractors for satisfactory performance of their contracts no later than 30 days from receipt of each payment the City of Ocala makes to the prime contractor, or as specified in the current F.S. 218.735, whichever time frame is earlier.
|
SAFETY AND ENVIRONMENTAL:
Vendor will be responsible at all times for precautions to achieve the protection of all persons including employees and property throughout the resulting contract term. The Vendor shall make an effort to detect hazardous conditions and shall take prompt action where necessary to avoid accident, injury or property damage. EPA, DEP, OSHA, and all other applicable safety laws and ordinances shall be followed as well as American National Standards Institute Safety Standards. All hazardous spills, accidents, injuries or claims or potential claims shall be reported promptly to the City Risk Management Department at 352-401-3989, or cell 352-572-0414, and rdennis@ocalafl.org.
Agrees to comply with the safety and environmental requirements above.
Owner/Authorized Company Representative initials:
|
SOLICITATION DOCUMENTS:
The City of Ocala (City) has no responsibility for the accuracy, completeness or sufficiency of any bid documents obtained from any source other than the official City links below:
Bid Ocala: www.bidocala.com
ProRFx Florida: www.florida.prorfx.com
Obtaining these documents from any other source(s) may result in obtaining incomplete and inaccurate information. Obtaining these documents from any source other than directly from the source listed herein may also result in failure to receive any addenda, corrections, or other revisions to these documents that may be issued.
|
SUBCONTRACTORS AND DBE GOALS:
The bidder represents the subcontractors listed below are financially responsible and are qualified, insured, licensed, and certified to do the work required.
The bidder will endeavor to use DBE/MBE subcontractors whenever possible. For non-grant funded projects, City of Ocala's goal is 15% as a race-neutral DBE goal. FDOT funded projects have a race-neutral DBE goal of 10.65%. The Ocala International Airport's DBE goal is 12%. SunTran's goal is 10.65%. DBE firms can be located via this directory: Florida Department of Transportation DBE Directory
No subcontractors will be utilized.
Our company will be utilizing more than two (2) subcontractors. Our list of subcontractors including percent of work is attached in the section labeled "REQUESTED AND ADDITIONAL DOCUMENTS." A fillable subcontractor list is available at: Subcontractor List
Bidder/Prime must perform a minimum of 30% of the work with their own forces unless specified differently in the Scope of Work.
NOTE: Bidder/Prime not providing an accurate, good faith estimate of subcontractor percent (%) of work may have their bid rejected.
|
SUBCONTRACTOR #1
|
Company Name:
Work Category:
City, State:
DBE MBE
|
Percent of Work: %
|
SUBCONTRACTOR #2
|
Company Name:
Work Category:
City, State:
DBE MBE
|
Percent of Work: %
|
TERMINATION:
2 C.F.R. § 200.339, 2 C.F.R. part 200, Appendix II (B)
All contracts in excess of $10,000 must address termination for cause and for convenience, including the manner by which it will be effected and the basis for settlement. For all contracts in excess of $10,000, the Termination clause extends to all third party contractors and their contracts at every tier and sub-recipients and their subcontracts at every tier.
a. Termination for Convenience (General Provision): The City of Ocala may terminate this contract, in whole or in part, at any time by written notice to the Contractor when it is in the City of Ocala’s best interest. The Contractor shall be paid its costs, including contract close-out costs, and profit on work performed up to the time of termination. The Contractor shall promptly submit its termination claim to City of Ocala to be paid the Contractor. If the Contractor has any property in its possession belonging to City of Ocala, the Contractor will account for the same, and dispose of it in the manner the City of Ocala directs.
b. Termination for Default [Breach or Cause] (General Provision): If the Contractor does not deliver supplies in accordance with the contract delivery schedule, or if the contract is for services, the Contractor fails to perform in the manner called for in the contract, or if the Contractor fails to comply with any other provisions of the contract, the City of Ocala may terminate this contract for default. Termination shall be effected by serving a Notice of Termination on the Contractor setting forth the manner in which the Contractor is in default. The Contractor will be paid only the contract price for supplies delivered and accepted, or services performed in accordance with the manner of performance set forth in the contract.
If it is later determined by the City of Ocala that the Contractor had an excusable reason for not performing, such as a strike, fire, or flood, events which are not the fault of or are beyond the control of the Contractor, the City of Ocala, after setting up a new delivery of performance schedule, may allow the Contractor to continue work, or treat the termination as a Termination for Convenience.
c. Opportunity to Cure (General Provision): The City of Ocala, in its sole discretion may, in the case of a termination for breach or default, allow the Contractor [an appropriately short period of time] in which to cure the defect. In such case, the Notice of Termination will state the time period in which cure is permitted and other appropriate conditions.
If Contractor fails to remedy to City of Ocala's satisfaction the breach or default of any of the terms, covenants, or conditions of this Contract within [10 days] after receipt by Contractor of written notice from City of Ocala setting forth the nature of said breach or default, City of Ocala shall have the right to terminate the contract without any further obligation to Contractor. Any such termination for default shall not in any way operate to preclude City of Ocala from also pursuing all available remedies against Contractor and its sureties for said breach or default.
d. Waiver of Remedies for any Breach: In the event that City of Ocala elects to waive its remedies for any breach by Contractor of any covenant, term or condition of this contract, such waiver by City of Ocala shall not limit City of Ocala’s remedies for any succeeding breach of that or of any other covenant, term, or condition of this contract.
e. Termination for Convenience (Professional or Transit Service Contracts): The City of Ocala, by written notice, may terminate this contract, in whole or in part, when it is in the City of Ocala’s interest. If this contract is terminated, the City of Ocala shall be liable only for payment under the payment provisions of this contract for services rendered before the effective date of termination.
f. Termination for Default (Supplies and Service): If the Contractor fails to deliver supplies or to perform the services within the time specified in this contract or any extension, or if the Contractor fails to comply with any other provisions of this contract, the City of Ocala may terminate this contract for default. The City of Ocala shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. The Contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner or performance set forth in this contract.
If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the City of Ocala.
g. Termination for Default (Transportation Services): If the Contractor fails to pick up the commodities or to perform the services, including delivery services, within the time specified in this contract or any extension, or if the Contractor fails to comply with any other provisions of this contract, the City of Ocala may terminate this contract for default. The City of Ocala shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of default. The Contractor will only be paid the contract price for services performed in accordance with the manner of performance set forth in this contract.
If this contract is terminated while the Contractor has possession of City of Ocala goods, the Contractor shall, upon direction of the City of Ocala, protect and preserve the goods until surrendered to the City of Ocala or its agent. The Contractor and City of Ocala shall agree on payment for the preservation and protection of goods. Failure to agree on an amount will be resolved under the Dispute clause.
If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the City of Ocala.
h. Termination for Convenience or Default (Architect and Engineering): City of Ocala may terminate this contract in whole or in part, for City of Ocala's convenience or because of the failure of the Contractor to fulfill the contract obligations. The City of Ocala shall terminate by delivering to the Contractor a Notice of Termination specifying the nature, extent, and effective date of the termination. Upon receipt of the notice, the Contractor shall (1) immediately discontinue all services affected (unless the notice directs otherwise), and (2) deliver to the Contracting Officer all data, drawings, specifications, reports, estimates, summaries, and other information and materials accumulated in performing this contract, whether completed or in process. If the termination is for the convenience of City of Ocala, the Contracting Officer shall make an equitable adjustment in the contract price but shall allow no anticipated profit on unperformed services. If the termination is for failure of the Contractor to fulfill the contract obligations, City of Ocala may complete the work by contract or otherwise and the Contractor shall be liable for any additional cost incurred by the Recipient. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the Recipient.
i. Termination for Default (Construction): If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will ensure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provision of this contract, City of Ocala may terminate this contract for default. The City of Ocala shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the City of Ocala may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the City of Ocala resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the City of Ocala in completing the work.
The Contractor's right to proceed shall not be terminated nor shall the Contractor be charged with damages under this clause if:
1. The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of City of Ocala, acts of another contractor in the performance of a contract with City of Ocala, epidemics, quarantine restrictions, strikes, freight embargoes; and
2. The Contractor, within [10] days from the beginning of any delay, notifies City of Ocala in writing of the causes of delay. If, in the judgment of City of Ocala, the delay is excusable, the time for completing the work shall be extended. The judgment of City of Ocala shall be final and conclusive for the parties, but subject to appeal under the Disputes clause(s) of this contract.
If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of City of Ocala.
j. Termination for Convenience or Default (Architect and Engineering): The City of Ocala may terminate this contract in whole or in part, for the City of Ocala’s convenience or because of the failure of the Contractor to fulfill the contract obligations. The City of Ocala shall terminate by delivering to the Contractor a Notice of Termination specifying the nature, extent, and effective date of the termination. Upon receipt of the notice, the Contractor shall (1) immediately discontinue all services affected (unless the notice directs otherwise), and (2) deliver to the City of Ocala ‘s Contracting Officer all data, drawings, specifications, reports, estimates, summaries, and other information and materials accumulated in performing this contract, whether completed or in process. City of Ocala has a royalty-free, nonexclusive, and irrevocable license to reproduce, publish or otherwise use, all such data, drawings, specifications, reports, estimates, summaries, and other information and materials.
If the termination is for the convenience of the City of Ocala, the City of Ocala’s Contracting Officer shall make an equitable adjustment in the contract price but shall allow no anticipated profit on unperformed services.
If the termination is for failure of the Contractor to fulfill the contract obligations, the City of Ocala may complete the work by contact or otherwise and the Contractor shall be liable for any additional cost incurred by the City of Ocala.
If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of City of Ocala.
k. Termination for Convenience of Default (Cost-Type Contracts): The City of Ocala may terminate this contract, or any portion of it, by serving a Notice of Termination on the Contractor. The notice shall state whether the termination is for convenience of City of Ocala or for the default of the Contractor. If the termination is for default, the notice shall state the manner in which the Contractor has failed to perform the requirements of the contract. The Contractor shall account for any property in its possession paid for from funds received from the City of Ocala, or property supplied to the Contractor by the City of Ocala. If the termination is for default, the City of Ocala may fix the fee, if the contract provides for a fee, to be paid the Contractor in proportion to the value, if any, of work performed up to the time of termination. The Contractor shall promptly submit its termination claim to the City of Ocala and the parties shall negotiate the termination settlement to be paid the Contractor.
If the termination is for the convenience of City of Ocala, the Contractor shall be paid its contract close-out costs, and a fee, if the contract provided for payment of a fee, in proportion to the work performed up to the time of termination.
If, after serving a Notice of Termination for Default, the City of Ocala determines that the Contractor has an excusable reason for not performing, the City of Ocala, after setting up a new work schedule, may allow the Contractor to continue work, or treat the termination as a Termination for Convenience.
|
DELAYS AND DAMAGES:
The Bidder agrees to make no claim for extra or additional costs attributable to any delays or inefficiencies in the performance of this contract occasioned by any act by the City except as provided in the agreement. The Bidder also agrees that any such delay or inefficiency shall be compensated for solely by an extension of time to complete the performance of the work in accordance with the provision in the standard specification.
|
CONFIDENTIAL, PROPRIETARY, OR TRADE SECRET MATERIAL:
Bids or quotes received by the City pursuant to its solicitations are exempt from public disclosure until such time that the City provides notice of an intended decision or until thirty (30) days after opening the bids or quotes, whichever is earlier. If the City rejects all bids or quotes pursuant to this solicitation and provides notice of its intent to reissue the solicitation, then the rejected bids or quotes remain exempt from public disclosure until such time that the City provides notice of an intended decision concerning the reissued solicitation or until the City withdraws the reissued solicitation. A bid, quote, or reply shall not be exempt from public disclosure longer than twelve (12) months after the City's initial notice rejecting all bids, quotes, or replies.
ANY MATERIAL SUBMITTED IN RESPONSE TO THIS SOLICITATION WILL BECOME A PUBLIC RECORD PURSUANT TO CHAPTER 119, FLORIDA STATUTES. THIS INCLUDES MATERIAL WHICH THE RESPONDING BIDDER MAY CONSIDER TO BE CONFIDENTIAL, PROPRIETARY, OR A TRADE SECRET. ANY CLAIM OF CONFIDENTIALITY SHALL BE WAIVED UPON SUBMISSION, EFFECTIVE AFTER OPENING PURSUANT TO CHAPTER 119, FLORIDA STATUTES.
Owner/Authorized Company Representative initials:
|